Welcome to Ewood Contractors Inc. By accessing our website and utilizing our services, you agree to comply with and be bound by the following terms and conditions. Please read these terms carefully.

1. Service Agreement:

   • All services provided by Ewood Contractors Inc, including home renovations, fencing, and deck installations, are subject to a separate service agreement. This agreement will outline the scope of work, timelines, payment terms, and any other specific conditions related to the project.
   • Ewood Contractors Inc reserves the right to refuse service to anyone for any reason.

2. Payment Terms:

   • Payment terms will be specified in the service agreement. Typically, a deposit is required before the commencement of any project, with subsequent payments due as milestones are achieved.
   • Late payments may incur interest charges as specified in the service agreement.
   • Ewood Contractors Inc reserves the right to suspend work if payments are not received according to the agreed schedule.

3. Project Timelines:

   • Project timelines provided by Ewood Contractors Inc are estimates and are subject to change based on factors such as weather conditions, material availability, and unforeseen site conditions.
   • Ewood Contractors Inc will make reasonable efforts to adhere to the agreed-upon timelines and will communicate any significant delays to the client promptly.

4. Warranty:

   • Ewood Contractors Inc provides a warranty on workmanship for a specified period, as detailed in the service agreement. This warranty covers defects in workmanship but does not cover damage caused by misuse, neglect, or natural events.
   • Materials used in the projects are subject to the manufacturer’s warranty.
   • To make a warranty claim, clients must notify Ewood Contractors Inc in writing within the warranty period.

5. Intellectual Property:

   • All content on the Ewood Contractors Inc website, including logos, text, images, and designs, is the intellectual property of Ewood Contractors Inc and is protected by copyright laws.
   • You may not use, reproduce, or distribute any content from our website without our prior written consent.

6. Limitation of Liability:

   • Ewood Contractors Inc shall not be liable for any indirect, incidental, special, or consequential damages arising out of or in connection with our services or the use of our website.
   • Our liability is limited to the amount paid by the client for the specific service in question.

7. Governing Law:

   • These terms and conditions shall be governed by and construed in accordance with the laws of the Province of Alberta, Canada.
   • Any disputes arising out of or in connection with these terms and conditions shall be subject to the exclusive jurisdiction of the courts of Alberta.

8. Changes to Terms and Conditions:

   • Ewood Contractors Inc reserves the right to modify these terms and conditions at any time without prior notice.
   • The most current version of the terms and conditions will be posted on our website. Your continued use of our website and services constitutes acceptance of the revised terms.

9. Contact Information:

   • If you have any questions or concerns about these terms and conditions, please contact us at:
   • Address: 9007 135 Ave, Edmonton, AB, T5C 2L9
   • Phone: (587) 590-4205
   • Email: info@ewoodcontractors.com

By using our website and services, you acknowledge that you have read, understood, and agree to be bound by these terms and conditions.